INVITATION TO BID
OWNER City of Evanston
1200 Main Street
Evanston, Wyoming 82930
ARCHITECT Myers Anderson Architects
122 South Main Street, Suite 1
Pocatello, Idaho 83204
Phone: (208) 232-3741
Sealed Bids will be received by the City of Evanston at 1200 Main Street, Evanston WY 82930 until 2:00 PM on March 23, 2023 for the Evanston Roundhouse Roof Sections 1 & 2.
Bids will be opened and publicly read at the above hour and date in the City Hall Conference Room.
Scope of work includes the following: Removal of the existing roof gravel and to mechanically spud the flood coat from the surface of the built-up roof (BUR) membrane on Roundhouse Sections 1 & 2. New HD poly-iso coverboard is to be fully adhered to BUR membrane and then a fully adhered 80 mil single ply membrane is to be installed. All associated flashing and counterflashing to be reused or replaced. The whole roof will receive roughly 32,000 square feet of new cover board and single ply roofing.
A Prebid conference will be held at the project site, in the Roundhouse, Portland Rose Room, 1500 Main Street, Evanston, Wyoming 82930 at 2:00PM on March 9, 2023. This Prebid conference will be held in conjunction with the Evanston City Hall Roof Replacement Prebid conference. A tour of both project sites will follow the Prebid conference. Attendance is highly recommended.
Electronic bid documents may be obtained from the office of the Architect at no charge. Hard copies of the bid documents may be obtained from the office of the Architect for a nonrefundable charge of $300.00.
Bids will be received on a lump sum basis.
Bidders shall be qualified to do business and licensed in accordance with all applicable laws of the state and local governments where the Project is located.
All bids must be on the forms furnished; all blank spaces filled in and signed with the name and address of the Bidder. No disqualified bids will be read.
Bids shall be in accordance with the Bid Documents.
Your offer will be required to be submitted under a condition of irrevocability for a period of 30 days after submission.
ADDITIONAL PROVISIONS
WYOMING STATUES:
Many Wyoming State Statutes apply to the bidding and contracting for Public Works Project. Some of the major statutory requirements are summarized below: The successful bidder shall be responsible for knowing and complying with all applicable state statutes, including but not limited to, the statutes discussed below:
W.S. 16-6-102: 5% Resident contractor preference
W.S. 16-6-104: 5% Preference for Wyoming materials
W.S. 16-6-203: Resident Labor Preference
W.S. 27-3-502 (f): Wyoming Employment Security
The Bid shall be conditioned upon compliance with all labor related requirements including the regulations and stipulations concerning equal employment opportunity, minority manpower utilization and affirmative action requirements. The Owner hereby notifies all prospective bidders that they will affirmatively assure that Small, Minority, and Women-Owned business will be afforded full and equal opportunity to submit proposals in response to this invitation and are on the grounds of race, sex, age, color, or national origin in consideration for an award.
OWNER’S RIGHT TO REJECT
The Owner reserve the right to reject any or all Bids and to waive irregularities therein, and all Bidders shall agree that such rejection shall be without liability on the part of the Owner for any damage or claim brought by any Bidder because of such rejections, nor shall the Bidders seek any recourse of any kind against the Owner because of such rejections. The filing of any Bid in response to this invitation shall constitute an agreement of the Bidder to these conditions.
Advertisement Dates: February 24, 2023, March 3, 2023, March 10, 2023
By: City of Evanston
1200 Main Street
Evanston, Wyoming 82930
PUBLISHED: Feb 24, 2023, March 3,10, 2023 02246
INVITATION TO BID
OWNER City of Evanston
1200 Main Street
Evanston, Wyoming 82930
ARCHITECT Myers Anderson Architects
122 South Main Street, Suite 1
Pocatello, Idaho 83204
Phone: (208) 232-3741
Sealed Bids will be received by the City of Evanston at 1200 Main Street, Evanston WY 82930 until 2:00 PM on March 23, 2023, for the Evanston City Hall Roof Replacement.
Bids will be opened and publicly read at the above hour and date in the City Hall Conference Room.
Scope of work includes the following: Removal of the existing roof ballast and existing EPDM rubber roof. A new single ply EPDM rubber membrane is to be installed and existing roof ballast is to be replaced. All associated flashing and counterflashing to be reused or replaced. The whole roof will receive roughly 11,500 square feet of new single ply roofing.
A Prebid conference will be held in the Roundhouse, Portland Rose Room, 1500 Main Street, Evanston, Wyoming 82930 at 2:00 PM on March 9, 2023. This Prebid conference will be held in conjunction with the Evanston Roundhouse Roof Sections 1 & 2 Prebid conference. A tour of both project sites will follow the Prebid conference. Attendance is highly recommended.
Electronic bid documents may be obtained from the office of the Architect at no charge. Hard copies of the bid documents may be obtained from the office of the Architect for a nonrefundable charge of $300.00.
Bids will be received on a lump sum basis.
Bidders shall be qualified to do business and licensed in accordance with all applicable laws of the state and local governments where the Project is located.
All bids must be on the forms furnished; all blank spaces filled in and signed with the name and address of the Bidder. No disqualified bids will be read.
Bids shall be in accordance with the Bid Documents.
Your offer will be required to be submitted under a condition of irrevocability for a period of 30 days after submission.
ADDITIONAL PROVISIONS
WYOMING STATUES:
Many Wyoming State Statutes apply to the bidding and contracting for Public Works Project. Some of the major statutory requirements are summarized below: The successful bidder shall be responsible for knowing and complying with all applicable state statutes, including but not limited to, the statutes discussed below:
W.S. 16-6-102; 5% Resident contractor preference
W.S. 16-6-104: 5% Preference for Wyoming materials
W.S. 16-6-203: Resident Labor Preference
W.S. 27-3-502 (f); Wyoming Employment Security
The Bid shall be conditioned upon compliance with all labor related requirements including the regulations and stipulations concerning equal employment opportunity, minority manpower utilization and affirmative action requirements. The Owner hereby notifies all prospective bidders that they will affirmatively assure that Small, Minority, and Women-Owned business will be afforded full and equal opportunity to submit proposals in response to this invitation and are on the grounds of race, sex, age, color, or national origin in consideration for an award.
OWNER’S RIGHT TO REJECT
The Owner reserve the right to reject any or all Bids and to waive irregularities therein, and all Bidders shall agree that such rejection shall be without liability on the part of the Owner for any damage or claim brought by any Bidder because of such rejections, nor shall the Bidders seek any recourse of any kind against the Owner because of such rejections. The filing of any Bid in response to this invitation shall constitute an agreement of the Bidder to these conditions.
Advertisement Dates: February 24, 2023, March 3, 2023, March 10, 2023
By: City of Evanston
1200 Main Street
Evanston, Wyoming 82930
PUBLISHED: Feb 24, 2023, March 3,10, 2023 02246
INVITATION FOR BID
Sealed proposals will be received for the Reconstruct Taxiway A and SE Apron project, addressed to the Uinta County, Attention: Fort Bridger Airport – Taxiway A/SE Apron project, 225 9th Street, Evanston, WY 82933 until 3:00 pm local time on March 28, 2023, and then will be publicly opened and read. Bids received after the time fixed for the opening will not be considered. Bidders are advised to research delivery methods thoroughly if not hand-delivering bids.
An on-line pre-bid meeting will be held via Zoom at 11:00 am, local time March 14, 2023 for those interested contractors, subcontractors, and suppliers. The pre-bid meeting is not mandatory but is highly encouraged. Bidders can access the pre-bid zoom meeting with the following link or zoom ID: https://jubengineers.zoom.us/j/5825826666.
The project consists of, but is not limited to, the reconstruction of Taxiway A Connector (approximately 800 SY) and the Southeast Apron (approximately 3,500 SY) within their existing paved footprints at the Fort Bridger Airport, Fort Bridger, WY. Work includes removal of asphalt pavement and aggregate base, subgrade preparation with separation geotextile; crushed aggregate base course placement, bituminous surfacing; and striping. Additionally, two lighted airfield sign panels will be replaced.
Plans, Contract Documents and Specifications and any addenda are available at www.questcdn.com Project #8407462. You may download digital copies of the Bidding Documents (including any Addenda) from QuestCDN at www.questcdn.com upon payment of twenty-five dollars ($25.00). Log on to the website and enter Quest Project #8407462. Should you need assistance with this process, please contact QuestCDN at 952-233-1632. Partial sets of Bidding Documents will not be available from the Issuing Office. Bids will only be accepted from those registered QuestCDN plan holders.
Each bid must be accompanied by a certified check, cash, cashier’s check, or bid bond in an amount not less than 5% of the total bid.
CIVIL RIGHTS – TITLE VI
Uinta County, WY, in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252, 42 USC §§ 2000d to 2000d-4) and the Regulations, hereby notifies all bidders or offerors that it will affirmatively ensure that for any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full and fair opportunity to submit bids in response to this invitation and no businesses will be discriminated against on the grounds of race, color, national origin (including limited English proficiency), creed, sex (including sexual orientation and gender identity), age, or disability in consideration for an award.
The proposed contract is also under and subject to the following federal clauses:
The Owner’s award of this contract is conditioned upon Bidder satisfying the good faith effort requirements of 49 CFR §26.53.
As a condition of bid responsiveness, the Bidder must submit the following information with their proposal on the forms provided herein:
1) The names and addresses of Disadvantaged Business Enterprise (DBE) firms that will participate in the contract;
2) A description of the work that each DBE firm will perform;
3) The dollar amount of the participation of each DBE firm listed under 1);
4) Written statement from Bidder or Offeror that attests their commitment to use the DBE firm(s) listed under 1) to meet the Owner’s project goal;
5) Written confirmation from each listed DBE firm that it is participating in the contract in the kind and amount of work provided in the prime contractor’s commitment; and
6) If Bidder or Offeror cannot meet the advertised project DBE goal, evidence of good faith efforts undertaken by the Bidder or Offeror as described in appendix A to 49 CFR part 26. The documentation of good faith efforts must include copies of each DBE and non-DBE subcontractor quote submitted to the bidder when a non-DBE subcontractor was selected over a DBE for work on the contract.
The successful Bidder must provide written confirmation of participation from each of the DBE firms the Bidder lists in their commitment. This Bidder must submit the DBE’s written confirmation of participation with the proposal documents as a condition of bid responsiveness.
All required Federal Clauses including the labor provisions, and wage rates are included in the specifications and bid documents. Each bidder must supply all of the information required by the bid documents and specifications.
This project includes Federal funds and is subject to the wage provisions of the Federal Davis-Bacon, Wyoming Department of Workforce Services, and related acts.
Each bidder shall furnish the Statement of Bidders Pre-Qualifications to the OWNER with satisfactory evidence of their competency to perform the work contemplated with the bid.
Uinta County, WY reserves the right to reject any and all proposals, waive any informalities, or irregularities, postpone the award of the Contract for a period not to exceed Ninety (90) days, and accept the proposal that is in the best interest of the Uinta County, WY The award of the Bid is contingent upon the receipt of Federal funding.
Dated this 24th day of March, 2023.
/S/ Jeff Breininger, Airport Manager
PUBLISHED: Feb. 24, March 3, 10, 2023 02245
INVITATION TO BID – (CRF2023)
The board of Uinta County Commissioners is accepting sealed bids for the price per ton for supplying and delivering of liquid Magnesium Chloride and the use of portable frac tanks (20,000 gallon min capacity) for dust suppression on Uinta County roads for the 2023 year.
Sealed bids will be accepted by Uinta County Clerk’s Office, PO Box 810, or 225 9th St Evanston, WY 82930 until 11:00 a.m. on March 20, 2023. All eligible bids having been received prior to this date and time will be publicly opened and read at 11:30 a.m. on March 20, 2023. The envelope must be marked as;MAGNESIUM CHLORIDE SEALED BID (CRF2023)”.
Bid documents can be picked up at the Uinta County Clerk’s office. Primary contact for this project is Saralee Gross, Uinta County Road & Bridge Administrative Assistant (307) 782-3254. Bid prices must be good for the 2023 construction season. In reviewing the bids received, Uinta County reserves the right to reject, for any reason whatsoever, any and all bids, and to waive any informality or irregularity in a bid. Uinta County will not be bound to accept the low bid, but rather the bid that is in the best interest of Uinta County.
UINTA COUNTY, WYOMING
PUBLISHED: February 24, March 3 & 10, 2023 02243
INVITATION TO BID (CM22304)
Notice is hereby given that the Board of Uinta County Commissioners are requesting bids for the Uinta County Dust Suppression Project. The successful contractor will be required to furnish all supervision, technical, personnel, labor, materials, machinery, tools, equipment, and services, including utility and transportation services to perform and complete all services and materials as defined in the bid documents.
Bid Documents are available from the Uinta County Clerk’s Office within the Uinta County Complex, 225 9th St. Evanston, Wyoming 82930
Sealed bids will be received at the Uinta County Clerk’s Office 225 9th St. Evanston, Wyoming until 11:00 a.m. local time, March 20, 2023. Bids should be marked on the outside;Uinta County Dust Suppression Project CM22304” with the name and address of the bidder. Primary contact for this project is Saralee Gross, Uinta County Road & Bridge Administrative Assistant (307) 782-3254.
Public opening of the bids will be on Monday, March 20, 2023 at 11:30 a.m. in the Uinta County Clerk’s Office, 225 9th St. Evanston, Wyoming. Bidders are welcome to attend.
This project is partially funded using Federal Grant Funds. Therefore, all Federal Requirements associated with the use of these funds must be followed.
All bids must be accompanied by either a certified check, cashier’s check drawn on an acceptable bank, or an acceptable BID BOND, executed by an approved Surety Company, in an amount not less than five percent (5%) of the total sum of the bid. The check or bond shall be made payable to Uinta County and shall be forfeited as liquidated damages if the bidder, upon the letting of the contract to him, fails to enter into the contract within thirty (30) days after it is presented to him for that purpose or fails to proceed with the performance of the contract in a timely manner.
All projects over $150,000.00 shall be bonded therefore the successful bidder shall provide a 100% performance and payment bond. All projects over $7500.00 or less than $150,000.00 require a form of guarantee as approved by the county.
The Board of Uinta County Commissioners hereby notifies all bidders that minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex, creed, or national origin.
Uinta County reserves the right to accept or reject any items or all items, any part or all parts, any section or all sections, any bid or all bids as stated in the specifications to waive any irregularities or informalities, or to re-bid or re-advertise for bids if it is determined to be necessary or desirable and reserve the right to let the bid in any manner it sees fit.
Uinta County will not be bound to accept the low bid, but rather the bid that is in the best interest of Uinta County.
UINTA COUNTY, WYOMING
David Mark Anderson, Chairman.
PUBLISHED: February 24, March 3 & 10, 2023 02242
NOTICE OF LIEN SALE
To:Stephen M. Ball - Notice is hereby given that on March 13, 2023, 12:00 p.m., at 75 Village Dr.Evanston, WY the undersigned will sell at public auction in accordance with 29-7-101 a 1985 GMC High Sierra, VIN 1GTEK14L4FJS30341, for the sum of $1,000, for services rendered.
Dated: Feb. 20, 2023 William and Shilo Rash
PUBLISHED: Feb.24, March 3, 2023 02247
INVITATION TO QUOTE
PROJECT NAME:
STREET STRIPING PROJECT; SUMMER 2023
SEALED QUOTES for STREET STRIPING (PAINTING) improvements will be received by the City of Evanston at the Department of Public Works, 33 Allegiance Circle, Evanston, Wyoming; until 1:00 p.m., THURSDAY, MARCH 9, 2023, at which time any and all Quotes received will be opened and read aloud. The successful Quoter shall furnish all labor, materials and equipment necessary for completion of the project.
Specification Documents may be obtained at the Department of Public Works: 33 Allegiance Circle; Evanston, WY 82930; Phone: (307) 783-6451; or e-mail cmaddux@evanstonwy.org. A hard copy requires a payment of $10.00 for each set; non-refundable. Registration at the office of the City of Evanston Public Works Dept. is required to receive full Quoting documents and to indicate residency status.
The OWNER reserves the right to reject all Quotes if the Governing Body determines that it is in the best interest of the City to do so.
City of Evanston
Gordon Robinson
Director of Public Works
PUBLISHED: Feb 24, and March 3, 2023 02241
PUBLIC NOTICE
Pursuant to the Wyoming Administrative Procedure Act and the Wyoming Public Service Commission’s (Commission) Procedural Rules, the Commission hereby gives notice of the Application of Rocky Mountain Power (RMP or the Company) for a non-situs Certificate of Public Convenience and Necessity (CPCN) to construct its Boardman-to-Hemingway transmission line as more fully described below:
PUBLISHED: Feb. 24, 31, 2023 02244
PUBLICATION OF WARRANTS
UINTA COUNTY SCHOOL DISTRICT NUMBER ONE, STATE OF WYOMING, PUBLICATION OF WARRANTS ISSUED AMOUNT TO $500.00 OR MORE, FOR THE MONTH OF JANUARY, 2023.
AFLAC PREMIUM HOLDING 1,653.35; BENEFICIAL LIFE INSURANCE COMPANY 873.49;DELTA DENTAL PLAN OF WY 46,946.35; EMPLOYEE BENEFIT FUND 607,095.84; HARTFORD 5,653.53; THE HARTFORD 7,543.22; THE HARTFORD INSURANCE CO 1,204.08; HARTFORD LIFE INSURANCE CO 12,268.19; NATIONAL BENEFIT SERVICES, LLC 799.30; NCPERS GROUP LIFE INS 800.00; VISION SERVICE PLAN 6,691.08; WY RETIREMENT SYSTEM 433,248.64; WYOMING DEPARTMENT OF WORKFORCE SERVICES 19,737.23; ACE RECYCLING & DISPOSAL 1,779.17; ALL WEST COMMUNICATIONS, INC” 6,791.69; PURCHASE POWER 3,000.00; TREERING WORKFORCE SOLUTIONS, INC. 1,426.75; WELLS FARGO FINANCIAL LEASING 741.00; AMAZON CAPITAL SERVICES 7,018.49; A+ TROPHY AND AWARDS 2,562.10; BEACON METALS./REX WILLIAMS DIVISION 10 1,171.49; REGION V BOCES 42,144.28; COKEVILLE SCHOOLS 1,014.06; WEX BANK/FLEET SERVICES 2,570.78; SWEETWATER COUNTY SCHOOL DIST. #2 600.00; HENSCHEID, BRANDON” 30,000.00; INSTRUCTIONAL INTENSITY INC 2,500.00; LARRY H. MILLER FORD 524.75; MARZANO RESEARCH LLC 6,480.00; MOUNTAINLAND SUPPLY COMPANY 7,374.87; NICHOLAS & COMPANY 972.00; PERSONNEL SCREENING SERVICES 1,243.50; PHYSICAL THERAPY SERVICES 3,500.00; PRESIDIO NETWORKED SOLUTIONS 69,476.03; SMITH PSYCHOLOGICAL SERVICES 1,600.00; SUBLETTE COUNTY SCHOOL DISTRICT #9 641.02; TETON SCIENCE SCHOOLS 7,316.40; TETON SCIENCE SCHOOLS 12,510.46; TONI J STUDIOS 530.00; BLUUM USA INC. 3,156.00; TYLER TECHNOLOGIES 976.22; VARSITY INK, LLC 2,861.80; CITY OF EVANSTON 7,592.14; CONTEST OF CHAMPIONS 52,508.00; PHILLIPS LAW, LLC 4,225.00; CASH 500.00; NATIONAL BENEFIT SERVICES, LLC 15,217.28; EPARS DEPARTMENT-REMITTANCE SERVICES 5,284.07; ORCHARD TRUST 6,402.08; WYOMING EDUCATION ASSOCIATION 3,611.57; DOMINION ENERGY 62,078.84; BAREFOOT 2,056.35; BEAR RIVER SIDING AND GUTTER LLC 3,750.00; BEST KIND 2,141.00; C.D.’S ELECTRIC 994.82; E2E EXCHANGE 9,090.00; FREEWAY TIRE, INC. 1,206.42; GILLETT DIESEL SERVICE INC 818.08; HM RECEIVABLES CO. II, LLC 1,901.25; MOUNTAIN ALARM FIRE 2,440.67; OPERATION PARENT 9,390.00; RELADYNE WEST LLC 57,682.52; SOLUTION TREE 5,200.00; SOUND SUPPORTS 3,037.50; TRANE U.S. INC. 3,775.50; HENGESTEG, ROBIN 500.00; ROCKY MOUNTAIN POWER 45,070.11; WELLS FARGO FINANCIAL LEASING 4,217.00; BEACON METALS./REX WILLIAMS DIVISION 10 10,911.25; C.D.’S ELECTRIC 9,294.15; DAVE NORRIS CONSTRUCTION 71,082.00; DOCUSIGN, INC 3,277.50; FILTER SERVICE & TESTING CORP. 3,600.00; INDUSTRIAL PIPE & WELDING LLC 151,371.84; INSTRUCTIONAL INTENSITY INC 6,250.00; JOHNSON COUNTY SCHOOL DISTRICT #1 2,000.00; KAJEET, INC. 4,142.85; PULSERA PROJECT, THE 1,451.00; SCHOLASTIC BOOK FAIRS 1,097.39; TOM’S HVAC 889.00; UINTA COUNTY HERALD 1,621.50; VENTRIS LEARNING LLC 14,700.00; VERIZON WIRELESS 1,868.06; NATIONAL BENEFIT SERVICES, LLC 15,300.62; EPARS DEPARTMENT-REMITTANCE SERVICES 5,705.96; ORCHARD TRUST 7,510.45; WYOMING EDUCATION ASSOCIATION 3,611.57; FIRST BANKCARD 60,553.72; ATIA Lockbox 4,020.00; BEST KIND 1,979.00; DENNIS, JARAUN 1,081.60; DIGITAL CITIZEN ACADEMY 1,500.00; DISABILITY:IN UINTA COUNTY 3,151.38; EPIC PRODUCTIONS LLC 500.00; INTERMOUNTAIN WOOD PRODUCTS 2,781.01; LAWRENCE’S 1,871.00; MARZANO RESOURCES LLC 12,800.00; PULSERA PROJECT, THE 933.00 ; SOLARWINDS, INC 923.00; SOLUTIONS FOR READING 930.00; TETON SCIENCE SCHOOLS 6,450.15; TOM’S HVAC 2,975.25; UINTA CO SCHOOL DIST #1 STUDENT ACTIVITY 3,959.30; WALMART COMMUNITY/GECRB 3,898.35; BROKEN ARROW 542.52; CAZIN’S 1,369.16; DERU’S GLASS WORKS 652.33; FLOYD’S TRUCK CENTER WY 3,564.19; FRONTLINE TECHNOLOGY GROUP LLC 4,464.06; GILLETT DIESEL SERVICE INC 1,031.87; HOMAX OIL SALES INC. 972.45; JOSTENS 1,469.26; KALLAS NAPA AUTO PARTS 2,269.58; LEWIS BUS GROUP 520.41; NICHOLAS & COMPANY 66,932.48; NYSTROM 1,120.00; PERSONNEL SCREENING SERVICES 1,114.50; PETROLEUM EQUIPMENT CO 912.50 PHOENIX LEARNING SYSTEMS RICHARD JAMES 2,887.50; PREMIER TRUCK GROUP 2,962.59; REAL KLEEN JANITORIAL 31,790.20; RESTAURANT & STORE EQUIPMENT 58,647.00; UNIVERSAL ATHLETICS LLC 1,564.37;WESTERN WYOMING BEVERAGES 2,914.40;
I, W DAN WHEELER,CLERK, UINTA COUNTY SCHOOL DISTRICT NUMBER ONE, STATE OF WYOMING, DO HEREBY CERTIFY THE WITHIN FOREGOING TO BE CORRECT.
PUBLISHED: Feb. 24, 2023 02246
NOTICE TO CREDITORS
Inter Vivos Revocable Trust of Charmaine Hoffman, Deceased
Pursuant to Section 75-7-508, Utah Code Annotated, Kelley Gene Hoffman, whose address is 730 East Main, Cokeville, Wyoming 83114 as Trustee of The Charmaine Hoffman Family Living Trust dated November 9, 1983, hereby gives notice that Charmaine Hoffman, of Rich County, Utah, the Settlor of said Trust, died on January 2, 2023. Creditors of the deceased Settlor are hereby notified to deliver or mail their written claims to the Trustee at the address above within three months after the date of the first publication of this notice or be forever barred.
Date of first publication: Feb. 17, 2023.
DATED this 10 day of February, 2023. SEAL & KENNEDY
A Professional Corporation
By Kelly M. Kennedy, Attorney for Trustee
PUBLISHED: Feb. 17, 24, March 3, 2023 021711
FORECLOSURE SALE NOTICE
WHEREAS, default in the payment of principal and interest has occurred under the terms of a Promissory Note (the “Note”) dated August 7, 2020, executed and delivered by Benny J. Smith and Jami Lynn Cox (“Mortgagors”) to Mortgage Solutions of Colorado, LLC, and a real estate Mortgage (the “Mortgage”) of the same date securing the Note, which Mortgage was executed and delivered by said Mortgagors, to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Mortgage Solutions of Colorado, LLC, its successors and assigns as Mortgagee, and which Mortgage was recorded on August 7, 2020, at Reception No. 1090742, in Book 1099, at Page 672-687 in the public records in the office of the County Clerk and ex-officio Register of Deeds in and for Uinta County, State of Wyoming; and
WHEREAS, the Mortgage was assigned for value as follows:
Assignee: Servis One, Inc. DBA BSI Financial Services
Assignment dated: January 12, 2023
Assignment recorded: January 18, 2023
Assignment recording information: at Reception No. 1135252, in Book 2049, at Page 635-636
All in the records of the County Clerk and ex-officio Register of Deeds in and for Uinta County, Wyoming.
WHEREAS, the Mortgage contains a power of sale which by reason of said default, the Mortgagee declares to have become operative, and no suit or proceeding has been instituted at law to recover the debt secured by the Mortgage, or any part thereof, nor has any such suit or proceeding been instituted and the same discontinued; and
WHEREAS, written notice of intent to foreclose the Mortgage by advertisement and sale has been served upon the record owner and the party in possession of the mortgaged premises at least ten (10) days prior to the commencement of this publication, and the amount due upon the Mortgage as of February 10, 2023 being the total sum of $197,140.03, plus interest, costs expended, late charges, and attorneys’ fees accruing thereafter through the date of sale;
WHEREAS, the property being foreclosed upon may be subject to other liens and encumbrances that will not be extinguished at the sale. Any prospective purchaser should research the status of title before submitting a bid;
WHEREAS, if the foreclosure sale is set aside for any reason, the Purchaser at the sale shall be entitled only to a return of his/her/its money paid. The Purchaser shall have no further recourse against the Mortgagee, Mortgagor, Servicer or their attorneys;
NOW, THEREFORE Servis One, Inc. DBA BSI Financial Services, as the Mortgagee, will have the Mortgage foreclosed as by law provided by causing the mortgaged property to be sold at public venue by the Sheriff or Deputy Sheriff in and for Uinta County, Wyoming to the highest bidder for cash at 10:00 o’clock in the forenoon on March 15, 2023 at the information desk at the Uinta County Courthouse located at 225 9th Street, Evanston, WY 82930, for application on the above described amounts secured by the Mortgage, said mortgaged property being described as follows, to-wit:
Lot 26 in Block 7 of the Platts Addition, being located in the Town of Lyman, Uinta County, Wyoming, according to the plat recorded July 19, 1974, as Instrument No. 275265, in the office of the Uinta County Clerk.
With an address of 112 Clover Ct N, Lyman, WY 82937 (the undersigned disclaims liability for any error in the address).
Together with all improvements thereon situate and all fixtures and appurtenances thereto.
Mortgagee shall have the exclusive right to rescind the foreclosure sale during the redemption period. In the event that the sale is rescinded or vacated for any reason, the successful purchaser shall only be entitled to a refund of their purchase price and/or statutory interest rate.
Dated: January 31, 2023 Servis One, Inc.
DBA BSI Financial Services
By: Shelly M. Casares
Halliday, Watkins & Mann, P.C.
376 East 400 South, Suite 300
Salt Lake City, UT 84111
801-355-2886
HWM File # WY21068
PUBLISHED: Feb. 10, 17, 24, March 3, 2023 02102
NOTICE OF LIEN SALE
To Whom It May Concern: Notice is hereby given that on March 1, 2023, 9:00 a.m. at 63 Reay St., Evanston, WY, the undersigned will sell at public auction, a 1995 Freightliner, VIN 1FUYDCYB6SH587526, for the sum of $1,000 for storage fees.
DATED: Feb. 15, 2023
Robertson Transportation Inc. Towing & Recovery
PUBLISHED: Feb. 17, 24, 2023 02176
NOTICE OF LIEN SALE
To Whom It May Concern: Notice is hereby given that on March 1, 2023, 9:00 a.m. at 63 Reay St., Evanston, WY, the undersigned will sell at public auction, a 2005 International, VIN 1HTMKAA65H167504 for the sum of $1,000 for storage fees.
DATED: Feb. 15, 2023
Robertson Transportation Inc. Towing & Recovery
PUBLISHED: Feb. 17, 24, 2023 02176
NOTICE OF LIEN SALE
To Whom It May Concern: Notice is hereby given that on March 1, 2023, 9:00 a.m. at 63 Reay St., Evanston, WY, the undersigned will sell at public auction, a 2015 International, VIN 3HAWGSTR1FL719020, for the sum of $1,000 for storage fees.
DATED: Feb. 15, 2023
Robertson Transportation Inc. Towing & Recovery
PUBLISHED: Feb. 17, 24, 2023 02176
NOTICE OF LIEN SALE
To Whom It May Concern: Notice is hereby given that on March 1, 2023, 9:00 a.m. at 63 Reay St., Evanston, WY, the undersigned will sell at public auction, a 2003 Utility Trailer, VIN 1UYVS25354U163306, for the sum of $1,000 for storage fees.
DATED: Feb. 15, 2023
Robertson Transportation Inc. Towing & Recovery
PUBLISHED: Feb. 17, 24, 2023 02176
PUBLIC NOTICE
Notice is hereby given that Storage Stable , 51 Arrowhead drive in the City of Evanston , State of Wyoming, will sell the contents of the following unit by online bids at BID13.com. Bidding will begin Feb. 22 at 10 a.m. until Feb. 27 at 10 a.am.
Unit # 2 Geneva Arcos , 302 Cheyenne Dr. Evanston Wy. Unit #95 Kaycee Wall and Christy Fisher 172 Morgan Circle Evanston, Wy., Unit 112 Russell Delambert 124 Lincoln Ave. Evanston Wy. Unit 256 Jasson Stryker 100 Sunset ave. Evanston Wy. Unit 263 Nicole May 96 E Hayden Ave. Evanston Wy.
PUBLISHED: Feb. 17, 24, 2023 021712
NOTICE TO WATER USERS
The applications below were filed with the Division of Water Rights in Rich County, Utah. These are informal proceedings per Rule 655-6-2. Protests concerning an application must be legibly written or typed, contain the name and mailing address of the protesting party, STATE THE APPLICATION NUMBER PROTESTED, CITE REASONS FOR THE PROTEST, and REQUEST A HEARING, if desired. Also, A $15 FEE MUST BE INCLUDED FOR EACH APPLICATION PROTESTED. Protests must be filed with the Division of Water Rights on or before Mar. 16, 2023 either electronically using the Division`s on-line Protest of Application form, by hand delivery to a Division office, or by mail at PO Box 146300, Salt Lake City, UT 84114-6300. Please visit waterrights.utah.gov or call (801)538-7240 for additional information.
NEW APPLICATION(S)
21-1907 (A83655): Dean Ellis propose(s) using 0.25 ac-ft. from groundwater (Manorlands Estates) for DOMESTIC.
Teresa Wilhelmsen, P.E.
State Engineer
Published in Uinta Co. Herald on Feb. 17 & 24, 2023 02172
INVITATION TO BID
The City of Evanston will accept bids for four (4) 2023 or newer half ton pickup trucks, type 4x4.
Copies of the specifications may be btained at the City Hall Office, 1200 Main Street, Evanston, WY 82930, Phone (307) 783-6300.
Sealed bids will be accepted at the City Hall Office until 3:00 p.m., Wednesday, March 8, 2023, and publicly opened at that time.
PUBLISHED: Feb. 17, 24, 2023 021710
REQUEST FOR QUALIFICATIONS
ENGINEERING PROFESSIONAL SERVICES
NOTICE TO PROFESSIONAL ENGINEERING CONSULTANTS
The City of Evanston is seeking statements of interest and qualifications from Engineers interested in providing design-bid-build professional services for the construction of 9,000’ of water transmission line. The new transmission line will deliver water from the E Hill treatment plant and tanks to the twin ridge storage tank. Work will include professional design, permitting, public bid package, construction management (with observation reports) and project close out.
Information for Proposal Submittal is available from the City of Evanston by contacting the Engineering Department via Dean Barker: email at dbarker@evanstonwy.org and include on subject line “Twin Ridge Transmission Line” or by phone at 307-783-6453. Statement of qualifications will be due on March 9, 2023 before 4:00pm.
City of Evanston
1200 Main Street
Evanston, Wyoming 82930
PUBLISHED: Feb. 10, 17, 24, 2023 02103
****PUBLIC NOTICE****
Notice is hereby given that Uinta County School District Number One will be holding a Public Forum at 6:00 p.m. on Tuesday, February 28, 2023 in the boardroom of the Education Service Center at 537 Tenth Street, Evanston, Wyoming.
The purpose of the forum is to provide information to and receive input from the community regarding the installation of domes which will provide space for indoor activities such as athletic events, additional practice space, co-curricular activities, instructional areas, and community events. Information will include the scope of the project, square footage ranges, location, and funding options. The agenda includes a short presentation followed by a question and answer period, and time for public comment.
The forum will be streamed live, and the link can be found on the district’s website (www.uinta1.com) or the district’s Facebook page the day of the notice. In addition, a link will be available on the district website, which will provide project plans and drawings. You are welcome to leave a comment following the forum via email at publiccomments@uinta1.com
PUBLISHED: Feb. 10, 17, 24, 2022 021010
STATE OF WYOMING ) IN THE DISTRICT COURT
COUNTY OF UINTA ) ss. THIRD JUDICIAL DISTRICT
David G. Bailey, Plaintiff/Petitioner ) Civil Action Case
vs Liza L. Castillo, Defendant/Respondent ) No. 23-DR-8
NOTICE BY PUBLICATION
Notice to Liza L. Castillo, current known address 900 Sundance Ave., Evanston, WY 82930. You are notified that a Complaint for Divorce has been filed in the Wyoming District Court for the Third Judicial District, 225 9th St, Evanston, WY 82930 seeking dissolution of your marriage to David G. Bailey and a decree of divorce. Unless you file answer or response or otherwise respond within 30 days following the last date of publication of this notice, a default judgment will be taken against you and a Decree of Divorce will be granted.
DATED this 24th day of January, 2023
Kerri Wright, Clerk Of District Court /s/ Trisha Tobiason, Deputy
PUBLISHED: Feb. 3, 10, 17, 24, 2023 02033
