3-20-2020 Uinta County Herald Legal Notices


INVITATION TO BID

Sealed  bids  for  the  Evanston  Housing  Authority  Saddle  Ridge  Apartment  Complex  Siding,  Soffit  and  Fascia  Replacement  Project  located at  250  Saddle Ridge  Road,  Evanston, Wyoming  82930,  will be received until  4:30 P.M. April  16, 2020  and  then publicly

opened and read aloud at the Owners office located at 155 Apache Drive, Evanston, Wyoming. Contractors are encouraged to visit the site to become familiar with the work before bidding. Contract David Albrecht at 307-789-2381 to schedule a site visit.

Bidding  Documents  can  be  downloaded  at  www.questcdn.com  under  Login using  QuestCDN  eBidDoc  #6916331 for a non-refundable charge  of  $35.00. Plan  holders  are parties  that  have downloaded  the  plans and  specifications.  Plan holders  will  be notified  via  email  as  addenda  are  issued.  Parties  that  download  the  plans  and  specifications  and  need  to  have  them  printed  elsewhere are solely responsible for those printing costs. The sales of paper copies for projects listed on this site are not available. Contact QuestCDN.com at 952-233-1632 or [email protected] for assistance in viewing or downloading with this digital project information. If you need further assistance, please contact David Albrecht at 307-789-2381.

The project consists of all labor and equipment necessary to remove; existing vinyl siding, trim and accessories, existing metal soffit and fascia, door and window casing. All labor, material, equipment, and incidentals for new; vinyl siding system, metal soffit and fascia, composite wood door casing and various blocking. The project includes six structures with a total footprint of 12,566 square feet with ±8-foot walls.

Each  Bidder  will  be  required  to  submit,  with  their  bid,  a  certified check,  or Bid Bond  made payable without condition to the  Evanston Housing Authority in the amount of not less than five percent (5%) of the Bidder’s maximum Bid Price as a guarantee that such Bidder will enter into a contract within fifteen (15) days after the date of the OWNER’S Notice of Award.

Successful Bidder shall comply with the Davis-Bacon Act.

Evanston Housing Authority reserves the right to reject any or all bids, or any part of any bid, to waive any formality in any bid, as its best interest may appear.

PUBLISHED: March 20, 27, 31, 2020   03206

NOTICE OF INTENT TO APPLY FOR TAX DEED

On 16 Sept.2015, Kerby and Ami Barker purchased the following real property for 2014 delinquent taxes, 185 Wood Ridge Lane, 2nd Amended Southridge Park SUB LT 154, Parcel #150-009892. The street address is: 185 Wood Ridge Lane, Evanston, WY. The property was taxed in the name of Gary W. Petersen. The present owner is Gary W. Petersen. There are no special assessments. The time for redemption will expire on July 7, 2020. Take notice that Kerby and Ami Barker will apply for a Tax Deed on July 7, 2020.This notice meets the statutory requirements of Wyoming Statutes. You are hereby notified above and as published.

NOTICE

TAKE NOTICE that on the 3rdday of March, 2020, the governing body of the City of Evanston, Uinta County, Wyoming, adopted a Resolution expressing its intent to vacate portion of The Ranch at Evanston Phase No. 1 Subdivision, which is more particularly described as follows, to-wit:

Part of The Ranch at Evanston Phase No. 1 Subdivision, City of Evanston, Uinta County, Wyoming, as said Subdivision, is platted and recorded in the Office of the Uinta County Clerk, and being more particularly described as follows:

Block 5:               Lots 1 through 9;

Block 6:               Lots 30 and 31;

Block 7:               Lots 8 through 12; Lots 14 through 27;

            Block 8:   Lots 1 through 4; Lots 7 through 10;

Block 9:               Lots 1 through 28;

            Block 10:Lots 1 through 10;

Block 11:             Lot 8;

            Block 12:Lots 7 and 8;

            Block 13:Lots 7 and 8;

            Block 14:Lots 7 and 8;

Wheatland Street: All;

Big Horn Lane: All;

            Saratoga Street: All;

            Tipton Lane: All;

            Rawlins Circle: All;

Riverton Circle: From a point perpendicular to the Northeast corner of Lot 28, Block 7, thence northerly, easterly, and southerly to a point perpendicular to the Northwest corner of Lot 13, Block 7;

Afton Avenue: From a point perpendicular to the Northeast corner of Lot 7, Block 7, thence easterly to the intersection with Newcastle Street;

Newcastle Street: From a point on the North boundary of Sundance Avenue, thence northerly to the Northerly boundary of said Subdivision.

The City of Evanston shall reserve all necessary easements for the construction, repair, replacement and maintenance of overhead and underground utilities, including but not limited to electrical lines, natural gas lines, water lines, sewer lines, storm sewer lines, television transmission lines and telephone lines.

On April 7, 2020, at 5:30 p.m., a public hearing will be held in the City Council Chambers of the Evanston City Hall, 1200 Main Street, Evanston, Wyoming, respecting said vacation. All protests, remonstrances and objections to the proposed vacation can be filed with the City Clerk of the City of Evanston, Wyoming, in writing, prior to or at the time set for the hearing. Public comments will also be received at the hearing;     

Dated this 17 day of March, 2020.

Nancy Stevenson, City Clerk

PUBLISHED: March 20, 27, April 3, 2020             03205

NOTICE

TAKE NOTICE that on the 3rdday of March, the governing body of the City of Evanston, Uinta County, Wyoming, adopted a Resolution expressing its intent to vacate the  Twin Ridge Subdivision No. 4 – Phase 5, which is more particularly described as follows, to-wit:

All of Twin Ridge Subdivision No. 4 – Phase 5, City of Evanston, Uinta County, Wyoming, as said subdivision is platted and recorded in the Office of the Uinta County Clerk.

The City of Evanston shall reserve all necessary easements for the construction, repair, replacement and maintenance of overhead and underground utilities, including but not limited to electrical lines, natural gas lines, water lines, sewer lines, storm sewer lines, television transmission lines and telephone lines.

On April 7, 2020, at 5:30 p.m., a public hearing will be held in the City Council Chambers of the Evanston City Hall, 1200 Main Street, Evanston, Wyoming, respecting said vacation. All protests, remonstrances and objections to the proposed vacation can be filed with the City Clerk of the City of Evanston, Wyoming, in writing, prior to or at the time set for the hearing. Public comments will also be received at the hearing;      Dated this 17 day of March, 2020.

 Nancy Stevenson, City Clerk

PUBLISHED: March 20, 27, April 23, 2020           03204

NOTICE

TAKE NOTICE that on the 3rd day of March, the governing body of the City of Evanston, Uinta County, Wyoming, adopted a Resolution expressing its intent to vacate  portion of the  Twin Ridge Subdivision No. 4 – Phase 4, which is more particularly described as follows, to-wit:

Part of the Twin Ridge Subdivision No. 4 – Phase 4, City of Evanston, Uinta County, Wyoming, as said subdivision is platted and recorded in the Office of the Uinta County Clerk, and being more particularly described as follows:

Lots 104-108; 

Lots 112-122;

Kelly Ann Circle: All;

Mary Lou Avenue: All

The City of Evanston shall reserve all necessary easements for the construction, repair, replacement and maintenance of overhead and underground utilities, including but not limited to electrical lines, natural gas lines, water lines, sewer lines, storm sewer lines, television transmission lines and telephone lines.

On April 7, 2020, at 5:30 p.m., a public hearing will be held in the City Council Chambers of the Evanston City Hall, 1200 Main Street, Evanston, Wyoming, respecting said vacation. All protests, remonstrances and objections to the proposed vacation can be filed with the City Clerk of the City of Evanston, Wyoming, in writing, prior to or at the time set for the hearing. Public comments will also be received at the hearing;      Dated this 17th day of March, 2020.

Nancy Stevenson, City Clerk

PUBLISHED: March 20, 27, April 3, 2020             03203

NOTICE BY PUBLICATION

Elia Elizabeth Valerio, Plaintiff               )

  1. Filipe de Jesus Ceballos, Defendant) Civil Action Case No. 19-197

Filipe de Jesus Ceballos, Defendant, address unknown, take notice that Elia Elizabeth Valerio has filed a Complaint for Divorce in the Wyoming District Court, Third Judicial District, whose address is 225 9th Street, Evanston, WY 82930, in Civil Action No. 19-197.You are required to answer the Complaint within thirty (30) days after last publication of this notice, failing which judgment by default will be rendered against you and a Decree of Divorce will be granted.

Kerry Bumgardner, Clerk of Court    /s/ Trisha Tobiason, Deputy

PUBLISHED: March 13, 20, 27, April 3, 2020      03132

INVITATION TO BID

PUBLIC WORKS PROJECT; MATERIALS AND CONSTRUCTION

PROJECT NAME:   HARRISON DRIVE STORM DRAIN REPLACEMENT

OWNER:

City of Evanston

1200 Main Street

Evanston, WY. 82930

SEALED BIDSfor construction of the HARRISON DR. STORM DRAIN REPLACMENT improvements will be received by the City of Evanston at the office of City Clerk located at 1200 Main Street (City Hall), Evanston, Wyoming; until 1:00 p.m., April 9, 2020at which time any and all bids received will be opened and read aloud.  The successful bidder shall furnish all labor, materials and equipment necessary for completing the project.

MATERIALS INCLUDE: Approximately; 380’ of 30” diameter HDPE storm drain pipe with imported bedding; erosion control BMP devices; precast manhole; concrete; Type “K” copper water service; traffic control devices and miscellaneous appurtenances.

WORK INCLUDES: Trench excavation; pipe installation; water service relocation; connection to existing manholes; pipe bedding; compacted backfill; hot mix asphalt street repair; traffic control; and miscellaneous work as necessary to complete the project. 

CONTRACT DOCUMENTS may be obtained at the Department of Public Works:City Engineer; 33 Allegiance Circle; Evanston, WY  82930; Phone: (307) 783-6453; Upon payment of $25.00 for each hard copy set; non-refundable.  No charge for electronic copy. Registration at the office of the City Engineer is required to receive full bidding documents and to indicate residency status.

WYOMING STATE STATUTES apply to the bidding and construction of this Public Works Project:

W.S. 15-1-113;  5% bid bond required.

W.S. 16-6-102;  5% resident contractor preference.

W.S. 16-6-104    5% Wyoming materials and suppliers preference.

W.S. 16-6-112;  performance guarantee.

W.S. 16-6-201 – 16-6-206;                 resident labor preference.

W.S. 27-3-502(f)                 registration with taxing authority.

RESIDENT PREFERENCE(S): In order to receive a five percent (5%) resident preference, resident contractors and material suppliers must be state certified and receive a certificate of residency.  When obtaining project bid documents, resident contractors and suppliers must  indicate their residency status by providing their residency certification number.  Certified resident suppliers shall submit a list of supplies and materials, specific to the project, which qualify to receive preference along with company contact names and phone numbers.   Contact information from resident suppliers shall be available to resident contractors to use in preparing bids and meeting Wyoming statutory requirements.

The OWNER reserves the right to reject all bids if the Governing Body determines that it is in the best interest of the City to do so.

The completion date for the project shall be June 15, 2020.

City of Evanston Public Works contact information:

Dean Barker       307-783-6453    or   [email protected]

                         (If emailing, include project name on subject line)

City of Evanston

Kent Williams, Mayor

PUBLISHED: March 20, 24, 27, 2020   03201

PUBLIC NOTICE

Notice is hereby given that Joshua and Arlena Harmon have applied for a Subdivision Permit for Lots 1 and 2 of the Harmon Subdivision located in Section 35, T13N, R117W, 6th P.M., Uinta County, Wyoming. A public hearing on this application will be held before the Uinta County Planning and Zoning Commission at 7:00 pm, Wednesday, March 25 in the Commission Chambers of the Uinta County Complex, 225 9th Street Evanston, Wyoming.

PUBLISHED: March 13, 20, 2020          03134

IN THE THIRD JUDICIAL DISTRICT COURT

IN AND FOR THE COUNTY OF UINTA, STATE OF WYOMING

BRENT JORGENSEN,                                                          )      CV-20-42

Plaintiff,                                                                                     )

  1. )

THOMAS LYNN SYDDALL, EMILEE ELSEN,           )

AMANDA PHILLIPS, THAD MONSENSYDDALL    )

and LINDSAY JAN MARTINEZ, heirs of Julie              )

Monsen, a deceased person, and DOE I to DOE IV,        )

unknown persons claiming an interest in the subject       )

matter of this proceeding,                                                      )

Defendants.                                                                               )

NOTICE OF COMPLAINT TO QUIET TITLE

TO: Claimants in Real Property at 312 Worland Cir., Evanston, Wyoming

YOU ARE HEREBY NOTIFIED that you have been sued in the District Court of the Third Judicial District for Uinta County, Wyoming by Brent Jorgensen in Civil no. CV-20-42. The attorney for Brent Jorgensen is George L. Arnold, Arnold Law Offices, 20 Yellow Creek Rd., Evanston, Wyoming 82930.

YOU ARE FURTHER NOTIFIED that the object and prayer of the complaint is to quiet title against you and all other parties claiming an interest in the real property located at 312 Worland Cir., Evanston, Wyoming, that has the legal description of The Ranch Subdivision, Phase 1, Block 2, Lot 4, in Uinta County, Wyoming (the “real property”).

YOU ARE FURTHER NOTIFIED that you are required to answer the Plaintiff’s Complaint to Quiet Title on or before thirty (30) days after the date of the last publication of this notice or said complaint will be taken as true and judgment by default will be rendered against you if you fail to appear.

DATED 2nd day of March, 2020.

         ORIGINAL SIGNED BY

         By:  /s/KERRI WRIGHT

(Seal of District Court)      Clerk of District Court

PUBLISHED:March 6, 13, 20, 27, 2020                  03063

INVITATION TO BID

Notice is hereby given that the Board of Uinta County Commissioners are requesting bids for the Uinta County Dust Suppression Project.  The successful contractor will be required to furnish all supervision, technical, personnel, labor, materials, machinery, tools, equipment, and services, including utility and transportation services to perform and complete all services and materials as defined in the bid documents.

Bid Documents are available from the Uinta County Planning Office within the Uinta County Complex, 225 9thSt. Evanston, Wyoming 82930

Sealed bids will be received at the Uinta County Planning Office. 225 9thSt. Evanston, Wyoming until 1:00 P.M. local time, March 27, 2020.  Bids should be marked on the outside “Uinta County Dust Suppression Project” with the name and address of the bidder.  Primary contact for this project is Kent Williams, Uinta County Planner (307) 783-0318.

Public opening of the bids will be on Friday, March 27, 2020 at 1:30 P.M. in the Uinta County Planning Office, 225 9thSt. Evanston, Wyoming.  Bidders are welcome to attend.

This project is partially funded using Federal Grant Funds.  Therefore, all Federal Requirements associated with the use of these funds must be followed.

All projects over $150,000.00 shall be bonded therefore the successful bidder shall provide a 100% performance and payment bond.  All projects over $7500.00 or less than $150,000.00 require a form of guarantee as approved by the county.

The Board of Uinta County Commissioners hereby notifies all bidders that minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex, creed, or national origin.

Uinta County reserves the right to accept or reject any items or all items, any part or all parts, any section or all sections, any bid or all bids as stated in the specifications to waive any irregularities or informalities, or to re-bid or re-advertise for bids if it is determined to be necessary or desirable and reserve the right to let the bid in any manner it sees fit.

Uinta County will not be bound to accept the low bid, but rather the bid that is in the best interest of Uinta County.

UINTA COUNTY, WYOMING

Eric South, Chairman.

PUBLISHED: March 6, 13, 20, and 27, 2020         03064

 

Advertisement